Effective Date: 19-07-2025

Welcome to Codebotics. These Terms and Conditions govern your access to and use of our website https://www.codebotics.com and any services provided by Codebotics. By using our website or engaging with our services, you agree to comply with and be bound by these terms. If you do not agree, please refrain from using our site or services.

1. Use of Our Website

You agree to use our website for lawful purposes only. You must not:

  • Violate any applicable laws or regulations
  • Interfere with or disrupt the functionality of our site
  • Attempt to gain unauthorized access to our servers or systems
  • Submit false, misleading, or harmful information through our contact forms

2. Services and Deliverables

Codebotics provides services such as web development, design, automation, and related digital solutions. The details, scope, and timeline of each project will be outlined in a separate proposal or contract before the start of work.

We reserve the right to accept or decline any project request at our discretion.

3. Payment Terms

All project fees, payment schedules, and milestones will be defined in the project agreement. Unless otherwise stated:

  • Payments are due as agreed upon in the invoice or proposal
  • Late payments may result in delays or suspension of work
  • All payments are non-refundable once services have been rendered or development work has begun

4. Intellectual Property

Unless agreed otherwise in writing:

  • Codebotics retains the rights to code, design, and other materials created until full payment is received
  • Once paid in full, ownership of the final deliverables will be transferred to the client
  • We reserve the right to showcase completed work in our portfolio unless a non-disclosure agreement (NDA) is in place

5. Third-Party Tools and Integrations

We may use third-party tools or services (e.g., hosting providers, plugins, APIs) as part of our project delivery. Codebotics is not responsible for downtime, pricing changes, or security vulnerabilities introduced by third-party services.

6. Limitation of Liability

Codebotics is not liable for:

  • Any indirect or consequential losses resulting from the use of our website or services
  • Delays or failures caused by factors beyond our control (e.g., server outages, third-party issues)
  • Any data loss or security breach not directly caused by our negligence

Use of our services is at your own risk.

7. Termination

Either party may terminate a service agreement with written notice. Codebotics reserves the right to discontinue services if a client violates these terms, becomes uncooperative, or fails to meet payment obligations.

8. Changes to These Terms

We may revise these Terms and Conditions at any time. Changes will be effective once posted on this page. Continued use of our website or services indicates your acceptance of the updated terms.

9. Governing Law

These Terms are governed by and interpreted in accordance with the laws of [Insert Your Country/Region]. Any legal disputes shall be resolved in the courts of [Insert Your Jurisdiction].

10. Contact Us

If you have any questions about these Terms and Conditions, please contact:

Codebotics
Email: info@codebotice.io
Website: https://www.codebotics.com